INVITATION TO BID – LIBERTY COUNTY EMS
PROJECT
Sealed bids from General Contractors will be received by the Liberty County Clerk’s Office until 3:00 PM Eastern Standard Time on Thursday, March 06, 2025, located at 10818 FL-20, Bristol, Florida 32321, for the Liberty County EMS. Bids will be publicly opened by the Liberty County Clerk at 3:15 PM Eastern Standard Time on Thursday, March 06, 2025, located at 10818 FL-20, Bristol, Florida 32321. Sealed bids can be mailed or hand delivered to the Liberty County Clerk of Courts Office at 10818 FL-20, Bristol, Florida 32321, and should be clearly labeled on the envelope ‘SEALED BID: Liberty County EMS.’ The bids will be publicly announced during the Liberty County Board of County Commissioners meeting on March 6, 2025.
LOCATION
Property to the North of 10979 NW Spring Street, Bristol, Florida 32321
OWNER
Liberty County Board of County Commissioners.
PROJECT DESCRIPTION
The construction project is for an EMS facility located in Bristol, Florida. The facility will include meeting rooms, a breakroom/kitchen, restrooms, offices, bunk spaces, living quarters, a truck bay, and a storage space. The project scope includes, but is not limited to: Site work, Cast-in-place concrete, CMU, Interior framing, Insulation, Interior flooring, Metal Siding, EIFS, Cementitious Siding, Awnings, Metal Roofing, Storefront Doors/Windows, HVAC, Plumbing, Electrical, Joint sealants, Painting, ng and Pre-Engineered Building Systems. All project elements will be bid as a single comprehensive package.
TYPE OF BID
The contract shall be awarded to the lowest responsible and responsive bidder whose bid meets the requirements and criteria outlined in the Contract Documents and in this Invitation to Bid. The Contract will be awarded on a lump sum basis.
No bid may be withdrawn for a period of thirty (30) days after time has been called on the date of opening. A Bid Bond in an amount not less than 5% of the Base Bid must accompany bids, and a Performance Bond and Payment Bond in an amount equal to 100% of the contract amount will be required of the successful bidder.
MANDATORY PRE-BID MEETING
A mandatory pre-bid meeting will be held on site on Thursday, February 06, 2025, at 4:00 PM Eastern Standard Time.
PRE-BID QUESTIONS
All questions requiring this project should be addressed in written form to the office of the Architect by contacting Doug Shuler, AIA (dshuler@bfbsa.com). The last day to ask questions will be Friday, February 21, 2025, at 5:00 P Eastern Standard Time.
TIME OF SUBSTANTIAL COMPLETION
The time limit for substantial completion of this work will be 456 (15 Months) calendar days from the Date of Commencement.
BID DOCUMENTS
Digital bid documents are available from the office of the Architect, BFBS Architects, 2074 Centre Pointe Boulevard, Suite 200, Tallahassee, Florida, 32308. A bidder’s list will be available from the Architect. Only Florida Licensed General Contractors may obtain plans and specifications by contacting Doug Shuler, AIA, (dshuler@bfbsa.com) at the office of the Architect.
Bidders are cautioned that acquisition of Bidding Documents through any other source is not advisable. Acquisition of Bidding Documents from an unauthorized source places the bidder at risk of receiving incomplete or inaccurate information upon which to base a bid.
CONTRACT
The successful bidder will be required to enter a written contract with the Liberty County Board of County Commissioners consistent with the form contract to be provided in the Bid Documents.
OWNERS’ RIGHT TO REJECT BIDS
The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that,t in their judgment,nt will be in the best interest of Liberty County. All bids shall remain firm for a period of sixty days after the opening.
All bidders shall comply with all applicable State and local laws concerning licensing, registration, and regulation of contractors doing business in the State of Florida. Liberty County encourages Minority Business Enterprises to respond to this Bid Invitation.